Resources

Client Alerts, News Articles, Blog Posts, & Multimedia

Everything you need to know about BMD and the industry.

UPDATE: COVID-19 Considerations for the Construction Industry

Client Alert
March 26, 2020

The implications of COVID-19 for the construction industry are significant and rapidly evolving, since Governor Mike DeWine instructed Ohioans to “stay at home” via Order (the “Order”) effective March 23, 2020.  Following are key takeaways for contractors:

May construction continue while the Order is in effect?

Yes.  Under Section 9, “Essential Infrastructure” includes “construction,” which is further defined to include, but not be limited to, an expansive list of types of construction. The Order further identifies “Essential Businesses” to include “Critical Trades,” defined at section 12(k), as “Building and Construction Tradesmen and Tradeswomen, and other trades including but not limited to plumbers, electricians … operating engineers, HVAC, painting … and other service providers who provide services that are necessary to maintaining the safety, sanitation, and essential operation of residences, Essential Activities, and Essential Businesses and Operations.”

Reading Sections 9 and 12 together, one may reasonably conclude that construction may continue in Ohio under the Order.

Must construction industry members perform existing obligations?

It depends. The answer to this question is most likely subject to the terms of the relevant contract, evaluated in the context of the Order. The Order arguably makes it more difficult to prove that the COVID-19 outbreak triggers force majeure clauses or other impossibility/impracticability provisions, because the Order permits construction to continue.   Construction industry members who seek to avoid contractual obligations as a result of COVID-19 do so at their own risk.

Must Owners still perform?

Not necessarily. Owners have discretion to defer or shut down a project. ODOT, for example, deferred two projects until 2021, after a worker in Cleveland tested positive and the site was shut down to sanitize. At the risk of stating the obvious, Owners will have a powerful argument that considerations of human health and welfare predominate over construction schedules.

Is it business as usual for contractors?

To a great extent, yes.  Be mindful of social distancing, as much as reasonably possible.  The Order requires Essential Businesses “at all times and as much as reasonably possible comply with Social Distancing Requirements.” The “Social Distancing Requirements” are as follows:

  • Required measures. Essential Businesses and Operations and businesses engaged in Minimum Basic Operations must take proactive measures to ensure compliance with Social Distancing Requirements, including where possible:
    • Designate six-foot distances. Designating with signage, tape, or by other means six-foot spacing for employees and customers in line to maintain appropriate distance;
    • Hand sanitizer and sanitizing products. Having hand sanitizer and sanitizing products readily available for employees and customers;
    • Separate operating hours for vulnerable populations. Implementing separate operating hours for elderly and vulnerable customers; and
    • Online and remote access. Posting online whether a facility is open and how best to reach the facility and continue services by phone or remotely.

 Other best practices?

  • Post the ‘Social Distancing Requirements’ at your physical office, on the job site and ensure each employee receive a copy.
  • Provide hand sanitizer and sanitizing products at key locations at your office and on job sites. Such locations may be areas with heavy traffic such as points of entry/exit, restrooms, equipment with multiple users, etc…
  • Though not part of the Order, it is recommended to require employee temperatures daily. Temporal thermometers provide a non-invasive option.  The State recommend anyone with a temperature above 100.4 degrees stay home.
  • Continue to consult BMD’s Triage Checklist to ensure your business is prepared for this ever-changing environment.

COVID-19 and Your Construction Business- A Triage Checklist:

Many business operations are shutting down at an alarming pace.  The coronavirus (“COVID-19”) pandemic is already impacting the construction industry and creating uncertainty for the progress of current and future projects.  Small/mid-size businesses may not be in financial position to sustain prolonged economic revenue declines.  Navigating the next few months will be vital in preserving existing business relationships and planning for future business when the conditions improve.  BMD offers some practical advice to manage risks and take reasonable precautions during this pandemic.  The following checklist is designed to help you identify prudent actions so you can successfully navigate the unknown future:

Prioritize the Health and Welfare of Your Employees and Clients:

  • Make sure your employees, contractors, suppliers and facilities are safe and smart - Forced quarantine will result in labor shortages and shutdowns
  • Over-communicate about best safety practices with employees and clients
  • Assess current projects and enforce heightened safety obligations
    • Ongoing projects in medical facilities? Nursing homes? Schools?
    • Mandatory temperature testing prior to entering healthcare facilities
    • Daily questionnaires regarding potential safety basics
    • Anything from washing hands to properly shielding coughs
  • Consult the CDC and/or State departments of health for guidance. Ex: https://www.cdc.gov/coronavirus/2019-ncov/downloads/workplace-school-and-home-guidance.pdf

Run Your Business:

  • Create and enforce an effective company policy approved by your employment attorney
  • Internal communications are vitally important
    • Promote safe practices in the workplace
    • Identify essential staff and functions
    • Prepare, equip and train staff to work remotely, if possible or if deemed mandatory
  • Review Employment Policies and enact emergency policies, if necessary
    • Sick leave
    • Family medical leave
    • Performance expectations
    • Protocol for working remotely

Evaluate Current Projects:

  • Prioritize clients and proper allocation of resources for projects
  • Evaluate availability of workforce, now and in the future when workers become ill
  • Evaluate supply chain impact on materials and supplies
    • Inventory and ration materials where possible

Review Your Contracts:

  • Review current contracts
  • Do not assume you have an ‘out’
    • Not all construction contracts have ‘force majeure’ provisions
    • Consult §8.3.1 of the AIA A201 regarding circumstances that may be commonly described or accepted as ‘force majeure’ events
  • Consider negotiating a modification of existing contracts and key terms
    • Consult §1.1.1, 1.1.2, 2.5, 3.11, 4.1.2, 4.2.1, 5.2.3, 7, 8.3.1, 9.7, 10.3.2 of the AIA A201 regarding modification
      • Contract duration
      • The goods/services involved in the contract
        • Adding or subtracting goods/services covered in the contract
      • The payment terms
      • The delivery terms
    • Determine notification requirements if performance is impossible or impractical and you are seeking to delay or excuse performance
      • 15.1.6 and §15.1.3 of the AIA A201 provides guidance on claims for delay
    • Do not ‘Self Help’ or bury your head in the sand
      • Communication and transparency are vital
      • Be pro-active and reasonable

Review Your Insurance Policy:

  • Coverage for the treatment of infected employees
  • Coverage for lawsuits filed by employees or other parties relating to COVID-19 exposure
  • Coverage for loss of revenue associated with epidemics, pandemics, and viruses such as COVID-19, governmental shutdown, or limitation of access to an insured’s business
  • Loss of earnings caused by delays or government (foreign or domestic) actions
  • Provide proper written notice of claims to avoid waiver of rights

For questions, please contact your primary attorney, or any member of BMD's Construction Law practice group.

COVID-19Construction LawBMD's Construction Law Groupconstruction industrystay at home order
Client Alert

New OSHA Guidance for Workplaces Not Covered by the Healthcare Emergency Temporary Standard

June 11, 2021On June 10, 2021, OSHA issued an Emergency Temporary Standard (ETS) for occupational exposure to COVID-19, but it applies only to healthcare and healthcare support service workers. For a detailed summary of the ETS applicable to the healthcare industry, please visit https://youtu.be/vPyXmKwOzsk. All employers not subject to the ETS should review OSHA’s contemporaneously released, updated Guidance on Mitigating and Preventing the Spread of COVID-19 in the Workplace. The new Guidance essentially leaves intact OSHA’s earlier guidance, but only for unvaccinated and otherwise at-risk workers (“at-risk” meaning vaccinated or unvaccinated workers with immunocompromising conditions). For fully vaccinated workers, OSHA defers to CDC Guidance for Fully Vaccinated People, which advises that most fully vaccinated people can resume activities without wearing masks or physically distancing, except where required by federal, state, or local laws or individual business policies.Client Alert

Employer Liability for COVID-19 Vaccine Side Effects

June 9, 2021As employers encourage or require employees to obtain a COVID-19 vaccine, they should be aware of OSHA recording obligations and potential workers’ compensation liability. Though OSHA has yet to revise its COVID-19 guidance in response to the latest CDC recommendations, OSHA has revised its position regarding the recording of injury or illness resulting from the vaccine. Until now, OSHA required an employer to record an adverse reaction when the vaccine was required for employees and the injury or illness otherwise met the recording criteria (work-related, a new case, and meets one or more of the general recording criteria). OSHA has reversed course and announced that it will not require recording adverse reactions until at least May 2022, irrespective of whether the employer requires the vaccine as a condition of employment. In its revised COVID-19 FAQs, OSHA states:Client Alert

The New Rule 1.510 - Radical Change for Summary Judgement Procedure in Florida

June 8, 2021In civil litigation, where both sides participate actively, trial is usually required at the end of a long, expensive case to determine a winner and a loser. In federal and most state courts, however, there are a few procedural shortcuts by which parties can seek to prevail in advance of trial, saving time, money and annoyance. The most common of these is the “motion for summary judgment”: a request to the court by one side for judgment before trial, generally on the basis that the evidence available reflects that a win for that party is legally inevitable and thus required. Effective May 1, 2021, summary judgment procedure in Florida has radically changed.Client Alert

Vacating, Modifying or Correcting an Arbitration Award Under R.C. 2711.13: Three-Month Limitation Maximum; Not Guaranteed Amount of Time

June 8, 2021In a recent decision, the Supreme Court of Ohio held that neither R.C. 2711.09 nor R.C. 2711.13 requires a court to wait three months after an arbitration award is issued before confirming the award. R.C. 2711.13 provides that “after an award in an arbitration proceeding is made, any party to the arbitration may file a motion in the court of common pleas for an order vacating, modifying, or correcting the award.” Any such motion to vacate, modify, or correct an award “must be served upon the adverse party or his attorney within three months after the award is delivered to the parties in interest.” In BST Ohio Corporation et al. v. Wolgang, the Court held the three-month period set forth in R.C. 2711.13 is not a guaranteed time period in which to file a motion to vacate, modify, or correct an arbitration award. 2021-Ohio-1785.Client Alert

EEOC Provides Updated Guidance Regarding Employer COVID-19 Vaccine Policies

June 3, 2021On May 28, 2021, the U.S. Equal Employment Opportunity Commission updated its guidance regarding employer COVID-19 vaccination policies. The new guidance provides much-needed clarification of expectations for employers seeking to promote workplace safety and prevent the spread of COVID-19, including discussion of mandatory vaccination policies, voluntary vaccination incentives, and accommodation of employees based on disability or sincerely held religious beliefs. The full text of the update is found in Section K of the EEOC’s COVID Q&A document. You can also learn more about these and other developments from BMD's Bryan Meek and Monica Andress through the Employment Law After Hours YouTube channel, available here.
Older posts
Newer posts